REPUBLIC OF SOUTH AFRICA
IN THE HIGH COURT OF SOUTH AFRICA
GAUTENG DIVISION, JOHANNESBURG
CASE NO: 2020-44579
DATE: 17 September 2025
In the matter between:
SELETJE CONSTRUCTION & MANAGEMENT CC Applicant
and
CITY OF EKURHULENI METROPOLITAN MUNICIPALITY Respondent
Neutral Citation: Seletje Construction & Management v City of Ekurhuleni
Metropolitan Municipality (2020-44579) [2025] ZAGPJHC ---
(17 September 2025)
Coram: Adams J
Heard: 20 May 2025
Delivered: 17 September 2025 – This judgment was handed down
electronically by circulation to the par ties' representatives by
email, by being uploaded to CaseLines and by release to SAFLII.
The date and time for hand -down is deemed to be 11:30 on
17 September 2025.
2
Summary: Arbitration – Arbitration Act 42 of 1965 – arbitral award declaring
cancellation of building contract invalid and unlawful – cancellation set aside
and specific performance of contract by respondent directed by the Arbitrator –
application to have arbitral award made an order of court in terms of s 31(1) of
the Arbitration Act – respondent opposing application on the basis that the
contract terminated by the effluxion of time – further grounds of opposition
raised in the form of a counter -application, such as the fact that the respondent
was entitled to cancel the contract due to breach of contract by the applicant –
further, respondent persisted with the defences raised during the arbitration –
claims that the specific performance orders of the Arbitrator should be varied or
set aside in terms of s 31(2) and s 33 of the Arbitration Act on the basis that the
respondent breached the agreement – respondent contends that the specific
performance order is against public policy –
Held that arbitral awards are binding on parties and should be set aside by a
court only on very limited grounds – an arbitral award should, on application by
any of the parties to the arbitration proceedings, be made an Order of Court,
unless valid grounds exist on which such an award falls to be set aside as
provided for in s 33 of the Arbitration Act – by agreeing to arbitration, the parties
had limited the grounds of interference in their contract by the courts to the
procedural irregularities set out i n s 33(1) of the Act – they had waived the right
to rely on any further grounds of review, whether at common law or otherwise -
the Act did not allow for review on the ground of material error of law and that
the general principle was that an irregularity related to the conduct of the
proceedings rather than to the merits –
Application granted and counterapplication dismissed.
3
ORDER
(1) The Arbitration Award dated 3 July 2021 by the Arbitrator, Mr P F
Rossouw SC, and handed down / published by him on 1 September 2021,
be and is hereby made an Order of this Court.
(2) The respondent shall pay the applicant’s costs of this opposed application,
including the costs of Counsel on scale ‘C’ of the applicable tariff provided
for in the Uniform Rules of Court.
(3) The respondent’s application for condonation be and is hereby dismissed
with costs.
(4) The respondent’s counter -application be and is hereby dismissed with
costs.
(5) The respondent shall pay the applicant’s costs of the opposed
condonation application and the oppose counter -application, such costs to
include the costs consequent upon the utilisation of Counsel on scale ‘C’
of the applicable tariff provided for in the Uniform Rules of Court.
JUDGMENT
Adams J:
[1]. Some six years ago on 4 April 2019, the applicant (‘Seletje Construction’)
and the respondent (‘City of Ekurhuleni’ or simply ‘the City’) concluded a written
agreement for the construction of the new Elandsfontein / Isando Fire Station in
Klopperpark, Germiston. The agreement was constituted by the JBCC Principal
Building Agreement, Edition 6.2 (‘the JBCC Agreement’), the Contract Data and
the ‘General Preliminaries’, and was concluded pursuant to and following a duly
compliant public procurement process . ‘JBCC’ is an acronym for ‘Joint Building
Contracts Committee’ and the Principal Building Agreement is a standard
4
agreement published by the said Committee in the interest of ‘… good practice,
with an equitable distribution of contractual risks’. The contract price agreed
upon was the total sum of R40 585 831.64 and the date for practical completion
of the contract provided for was 17 January 2021.
[2]. Seletje Construction was given possession of the site on 19 March 2019 ,
whereafter t he works commenced. However, between April 2019 and March
2020 numerous disputes arose between the parties , culminating in a purported
cancelation by the City of Ekurhuleni on 16 March 2020 of the agreement on the
basis of alleged malperformance and breach of contract by Seletje
Construction. From their side, Seletje Construction complained of non-payment
by the City of amounts due to them as interim progress payments – duly
certified as due and payable in terms of the contract. During March 2020, the
works came to a standstill.
[3]. During January 2021, in terms of the alternative dispute resolution
provisions of the agreement and an Order of this Court (per Yacoob J), the
dispute between the parties were referred to arbitration. Advocate P F Rossouw
SC, Senior Council at the Johannesburg Bar , was duly appointed as arbitrator,
by agreement between the parties, to arbitrate the dispute.
[4]. On 1 September 2021, Advocate Rossouw , after the arbitration
proceedings had proceeded before him, published his award dated 3 July 2021
(‘the arbitral award’) and directed as follows: -
‘(a) The City of Ekurhuleni must make payment to [Seletje Construction] of the
following amounts:
(i) R467 877.01 (excluding VAT) in respect of payment certificate number 11;
(ii) R9 535.27 as interest on the late payment of payment certificate number 1;
(iii) R32 637.19 as interest on the late payment of payment certificate number 2;
(iv) R90 587.25 as interest on the late payment of payment certificate number 10;
(v) R101 699.74 as interest on the outstanding payment of payment certificate
number 11;
5
(b) It is declared that [the City of Ekurhuleni] had no contractual basis or entitlement
to terminate the agreement concluded between the parties on 4 April 2019 and
the notice of termination dated 20 March 2020 is set aside;
(c) It is declared that [Seletje Construction] may remain in possession of the
construction site of the new Klopperpark Fire Station at 67 Welkom Street,
Klopperpark, Germiston, and that it may proceed with the execution of the Works
in terms of the agreement concluded between the parties on 4 April 2019;
(d) It is declared that [Seletje Construction] is entitled to be compensated for work
done during February 2020 (and not covered by payment certificate number 11)
and March 2020;
(e) The [City of Ekurhuleni] must pay the costs of the arbitral proceedings, including:
(i) the arbitrator's fees;
(ii) the costs of the venue of the hearing;
(iii) the costs of recording the proceedings and the transcription;
(iv) [Seletje Construction's] costs of reference, on the party and party High Court
scale, including the costs of Senior Council.’
[5]. The City of Ekurhuleni has complied with the payment requirements of
paragraphs (a) and (d) of the award and it has also made payment of the costs
awarded against it in favour of Seletje Construction in terms of paragraph (e) of
the award. That means that those portions of the award by the Arbitrator have,
for all intents and purposes , been rendered moot, and I need not concern
myself any further with those paragraphs of the award.
[6]. In t his opposed application, Seletje Construction applies to have the
award of the Arbitrator made an order of this court in accordance with the
provisions of s 31(1) of the Arbitration Act 42 of 1965. In essence, what Seletje
Construction prays for is an order that they be permitted to continue with the
contract, which expired during 2021, through no fault on their part.
[7]. The City of Ekurhuleni opposes the application and has somewhat
[7]. The City of Ekurhuleni opposes the application and has somewhat
belatedly instituted a counter -application – supported by a combined affidavit in
answer to Seletje’s application and the founding affidavit in support of the
counter-application – for an order declaring the agreement entered into between
6
the parties on 4 April 2019 to have terminated through effluxion of time . In the
alternative, the City applies for an order correcting – in terms of s 31(2) of the
Arbitration Act – paragraphs 60(b) and 60(c) of the arbitral award. In effect what
the City prays for in the alternative is an order limiting paragraphs (b) and (c) of
the award to provide specifically that the review and the setting aside of the
cancellation of the contract was based solely on the basis of its non -payment of
amounts due in terms of the contract during March 2020. There are prayers for
further alternative relief by the City, which I will deal with later in this judgment
insofar as that may be necessary. Suffice to state at this stage that the City
applies for an order declaring that paragraph 60(c) of the Award cannot be
enforced ‘… as, given the particular circumstances of the matter and the
constitutional and statutory obligations of [the City of Ekurhuleni] , enforcement
thereof is against public policy’.
[8]. Seletje Construction’s main application to have the arbitral award made
an Order of Court was delivered on or about 14 April 2022, and the City of
Ekurhuleni delivered notice of its intention to oppose on or about 11 May 2022.
The respondent’s answering affidavit was therefore required to be delivered in
terms of the Uniform Rules of Court within fifteen days from that date, therefore
on or before 1 June 2022. The combined answering / founding affidavit was
delivered on or about 29 August 2022 – therefore, out of time by some three
months. Some of the relief sought by the City in its counter -application, as will
become apparent later, was also required to be brought within limited periods of
time, which was not complied with by the City in its counter -application. All the
same, the City, as it was obliged to do, applies for condonation for the late filing
of its application and for the late filing of its answering affidavit . I deal with the
of its application and for the late filing of its answering affidavit . I deal with the
application for condonation as part of my decision on the merits of t he
application and the counter-application.
[9]. Therefore, the issue in this application is simply whether , all things
considered, Seletje Construction is entitled to an order for specific performance
of the agreement, notwithstanding the fact that, on first principles, the
agreement expired during January or June 2021. This issue is to be considered
7
by me having regard to the trite principles relating to arbitral awards in general
and those relating to the making of such awards orders of court. Those
principles are set out briefly in the paragraphs which follow.
[10]. Section 28 of the Arbitration Act provides as follows: -
’28 Award to be binding
Unless the arbitration agreement provides otherwise, an award shall, subject to
the provisions of this Act, be final and not subject to appeal and each party to the
reference shall abide by and comply with the award in accordance with its terms.’
[11]. Section 31 provides thus: -
’31 Award may be made an order of court
(1) An award may, on the application to a court of competent jurisdiction by any party
to the reference after due notice to the other party or parties, be made an order of
court.
(2) The court to which application is so made, may, before making the award an
order of court, correct in the award any clerical mistake or any patent error arising
from any accidental slip or omission.
(3) An award which has been made an order of court may be enforced in the same
manner as any judgment or order to the same effect.’
[12]. As was held by the Supreme Court of Appeal in Telcordia Technologies
Inc v Telkom SA Limited1, arbitral awards are binding on parties and should be
set aside by a court only on very limited grounds. This implies, in my view, that
an arbitral award should, on application by any of the parties to the arbitration
proceedings, be made an Order of Court , unless valid grounds exist on which
such an award falls to be set aside as provided for in s 33 of the Arbitration Act,
which reads as follows: -
’33 Setting aside of award
(1) Where –
(a) any member of an arbitration tribunal has misconducted himself in relation to
his duties as arbitrator or umpire; or
1 Telcordia Technologies Inc v Telkom SA Limited 2007 (3) SA 266 (SCA).
8
(b) an arbitration tribunal has committed any gross irregularity in the conduct of
the arbitration proceedings or has exceeded its powers; or
(c) an award has been improperly obtained,
the court may, on the application of any party to the reference after due notice to
the other party or parties, make an order setting the award aside.
(2) An application pursuant to this section shall be made within six weeks after the
publication of the award to the parties: Provided that when the setting aside of
the award is requested on the grounds of the commission of an offence referred
to in Part 1 to 4, or section 17, 20 or 21 (in so far as it relates to the
aforementioned offences) of Chapter 2 of the Prevention and Combating of
Corrupt Activities Act, 2004, such application shall be made within six weeks after
the discovery of that offence and in an y case not later than three years after the
date on which the award was so published.
(3) The court may, if it considers that the circumstances so require, stay enforcement
of the award pending its decision.
(4) If the award is set aside the dispute shall, at the request of either party, be
submitted to a new arbitration tribunal constituted in the manner directed by the
court.’
[13]. In Telcordia T echnologies the SCA explained the rationale behind the
foregoing principle as follows. By agreeing to arbitration, the parties had limited
the grounds of interference in their contract by the courts to the procedural
irregularities set out in s 33(1) of the Act. By necessary implication, they had
waived the right to rely on any further grounds of review, whether at common
law or otherwise. The Court also held that the Act did not allow for review on the
ground of material error of law and that the general principle was that an
irregularity related to the conduct of the proceedings rather than to the merits .
A qualification to that general principle is that a 'gross irregularity' was
A qualification to that general principle is that a 'gross irregularity' was
committed where the decision -maker misconceived the whole nature of the
enquiry, namely he misconceived his mandate or his duties in connection
therewith.
[14]. Importantly, it was h eld by the SCA that a wrong interpretation of an
agreement, for example, also did not entail the arbitrator's exceeding his
9
powers. The power given to him was to, rightly or wrongly, interpret the
agreement; determine the applicable law; and determine what evidence was
admissible. Errors of this kind had nothing to do with his exceeding his powers
but were errors committed by him within the scope of his mandate.
[15]. The question in casu is therefore whether the City of Ekurhuleni is
entitled to object to the arbitral award being made an Order of Court on the
basis of the defences raised by it. Put another way, do these grounds of
opposition warrant a deviation from the above general principle?
[16]. All of the foregoing issues in this matter are to be decided against the
factual backdrop. I deal with the facts in paragraphs which follow as and when I
deal with a discussion and an analysis of the matter.
[17]. As already indicated, the agreement was concluded between the parties
on 4 April 2019, Seletje Construction, as the contractor, having been given
possession of the construction site before that on 19 March 2019. Between April
2019 and February 2020 numerous site meetings were held at which the City
and/or its agents complained consistently as regards inter alia the slow
progress made with the contract , poor performance and workmanship on the
part of Seletje Construction and their failure to rectify defects . This ultimately
resulted in a notice of termination of the agreement on 20 March 2020 from the
City to Seletje, which cancellation was subsequently reviewed and set aside on
7 April 2020 by this Court, which also directed that the disputes between the
parties be referred to arbitration.
[18]. The arbitration proceedings commenced on 24 May 2021 , were
concluded on 2 June 2021 and the arbitral award dated 3 July 2021, as detailed
supra, was published on 1 September 2021.
[19]. Through its counter -application, the City of Ekurhuleni resist s the
application by Seletje on the basis of the grounds set out above. I now proceed
to deal in turn with those grounds of opposition.
10
[20]. Primarily, the City contends that the arbitral award should be set aside
because the agreement between the parties has terminated through the
effluxion of time. As already indicated, the agreement expressly made provision
for the 17 th of January 2021 as ‘the date for practical completion ’. On 20
January 2020, the contract term was extended by the City to 30 June 2021 and
the agreement, so the City contends, thus terminated through effluxion of time
on 30 June 2021.
[21]. In terms of clause 23 of the agreement, Seletje is, however, ‘entitled to a
revision of the date for practical completion’ with an adjustment of the contract
price in a number of circumstances. One such circumstance provide d for in
clause 23.2.13 is ‘Suspension of the works’. Importantly, clause 23.3 provides
as follows:
‘Further circumstances for which [Seletje Construction] may be entitled to a revision of
the date for practical completion and an adjustment of the contract value are delays to
practical completion due to any other cause beyond [Seletje’s] reasonable control that
could not have reasonably been anticipated and provided for. The principal agent shall
adjust the contract value where such delay is due to [the City of Ekurhuleni] and/or its
agents’. (Emphasis added).
[22]. In the alternative, the City applies for a declaratory order to the effect that
the contract has previously been validly terminated, alternatively had been
terminated upon the launching of its counter-application, consequent upon the
anticipatory breach (repudiation) of the contract by Seletje.
[23]. The first difficulty w ith this ground of opposition is the fact that clause 23
of the agreement, referenced above, is a complete reply to the case by the City
in that regard. The simple point is that, having regard to the circumstances in
the matter, notably the protracted disputes and litigation between the parties,
Seletje is fully entitled to apply for a revision of the date for practical completion.
Seletje is fully entitled to apply for a revision of the date for practical completion.
If nothing else, Seletje has the right to insist on a revision of the practical
completion date on the basis that, at the insta nce of the City, the Works were
suspended during March 2020 – approximately on e year after the
11
commencement of the contract and about one year before the date of practical
completion.
[24]. Moreover, the case on behalf of Seletje – which is not seriously disputed
on behalf of the City – is that, following publication of the award, it attempted to
resume performance in line with p rayer (c) of the Award , including a formal
request dated 10 November 2021. The City however failed to cooperate and
filed a notice to oppose enforcemen t, which amounts, in my view, to an
unequivocal refusal to comply with the award. For this reason too, the defence
should fail. The City cannot benefit from the very delay it caused. It obstructed
dispute resolution, unlawfully removed the contractor from site, and refused to
implement the award. It cannot now rely on the passage of time – which it
engineered – as a ground to argue that the contract expired.
[25]. What is more is that this issue is an issue which would have been before
the Arbitrator when he adjudicated the dispute relating to the cancellation of the
contract by the City. If it was not before him explicitly, it certainly was before him
by implication in that by the time the arbitration proceedings were conclude d
and the Arbitrator scripted the Award in close proximity to the date for practical
completion. He nevertheless directed specific performance of the contract by
the City of Ekurhuleni. Howsoever one views this matter, it has to be accepted
that this issue raised on behalf of the City is an issue which was before the
Arbitrator and was decided against the City, who now desires to have that issue
decided afresh as an appeal under the guise of an order setting aside the
Arbitrator’s Award.
[26]. There is accordingly no merit in this ground of opposition. As was held by
the SCA in Telcordia Technologies 2, the parties had limited the grounds of
interference in their contract by the courts to the procedural irregularities set out
in s 33(1) of the Act. By necessary implication, they had waived the right to rely
in s 33(1) of the Act. By necessary implication, they had waived the right to rely
on any further grounds of review, whether at common law or otherwise. In any
2 FN 1 supra.
12
event, if the City believes this issue to be a dispute between them at this stage,
then they are required, in accordance with Telcordia Technologies, to refer this
matter back to arbitration.
[27]. The City also contends that, e ven if this Court is of the view that the
agreement did not terminate on 30 June 2021 through effluxion of time, its
counter-application with its combined affidavit at the very least served as
reasonable notice to Seletje of the termination of the agreement for the reasons
mentioned in the said affidavit . In that regard, the City places reliance on an
expert report dated 22 July 2022, that is after the date on which the Arbitrator’s
award was published. This report regurgitates the grievances complained of by
the City in its notice of termination of the contract and which complaints were all
raised by them in the arbitration. The Arbitrator rejected this defence and held
that the City was not justified in cancelling the agreement.
[28]. The case on behalf of the City is that the agreement terminated through
the effluxion of time . Additionally, so the contention continues, the arbitrator
erred by holding that ‘ ... [the City of Ekurhuleni] relied on the wrong grounds for
the purported termination of the agreement .... the Agreement was not validly
terminated. [The City] remains obliged to give [Seletje] possession of the site
and the contractor may proceed with the works to bring it to practical completion
and eventually to final completion ’. This, so the contention is concluded, also
constitutes a patent error by the arbitrator as provided for under Section 31(2) of
the Arbitration Act.
[29]. I do not accept this contention and I do so for the reasons already
alluded to above. In particular, the City is bound by the findings of the Arbitrator
and it cannot apply for a review of the Award on the basis that the Arbitrator
made an error of fact or law. The point, which bears emphasis, is that e ven if
made an error of fact or law. The point, which bears emphasis, is that e ven if
the arbitrator had erred in assuming the contract remained extant, which in
effect would amount to an error of law or interpretation, it is not a gross
irregularity reviewable under section 33(1) of th e Arbitration Act. As was held in
Telcordia Technologies at para 86:
13
‘[86] Likewise, it is a fallacy to label a wrong interpretation of a contract, a wrong
perception or application of South African law, or an incorrect reliance on inadmissible
evidence by the arbitrator as a transgression of the limits of his power. The power
given to the arbitrator was to interpret the agreement, rightly or wrongly; to determine
the applicable law, rightly or wrongly; and to determine what evidence was admissible,
rightly or wrongly. Errors of the kind mentioned have nothing to do with him exceeding
his powers; they are errors committed within the scope of his mandate. To illustrate, an
arbitrator in a “normal” local arbitration has to apply South African law but if he errs in
his understanding or application of local law the parties have to live with it. If such an
error amounted to a transgression of his powers it would mean that all errors of law are
reviewable, which is absurd.’
[30]. This principle, in my view, finds application in casu.
[31]. Moreover, the reliance by the City of Ekurhuleni on the provisions of
s 31(2) of the Arbitration Act is misplaced. By no stretch can it be said with any
conviction that the arbitral award contained a ‘ clerical mistake or any patent
error arising from any accidental slip or omission ’, which require correction by
this Court. There most certainly is no evidence before me in support of a finding
to that effect.
[32]. The aforegoing also apply to the other grounds of opposition raised by
the City, in particular its claim that the arbitral Award should be set aside on the
basis that making the Award an Order of Court would be significantly prejudicial
and contrary to public policy . The City alleges that Seletje Construction has not
only neglected to comply with its obligations under the agreement but is also
clearly incapable of complying with those o bligations. Therefore, so the
contention goes, it would therefore be against public policy to compel the City to
contention goes, it would therefore be against public policy to compel the City to
comply with its obligations in terms of the agreement. The aforegoing is
illustrated, so the City contends, through the expert evidence alluded to supra,
which proves that Seletje is incapable of performing its obligations in terms of
the agreement to render a fire station compliant with the standards and code of
practice as referred to by the expert, Mr van Straten.
14
[33]. I reiterate that this defence has no merit. It is also an issue which should
be arbitrated as prescribed by the agreement, as is the ground of opposition
raised by the City as an application for the purported c orrection of prayers (b)
and (c) of the arbitra l award in terms of s 31(2) of the Arbitration Act,
alternatively that these prayers ( b) and (c) of the award be reviewed and set
aside in accordance with the provisions of s 33(1)(b) and (2) of the Arbitration
Act, with the period of six weeks to be extended in accordance with the
provisions of s 38 of the Arbitration Act to date of service and filing of the City’s
counter-application.
[34]. I therefore conclude that t he arbitration award issued on 1 September
2021 remains valid, final and binding. Seletje Construction has satisfied all the
requirements of section 31(1) of the Arbitration Act for enforcement. There is no
merit in any of the grounds of opposition raised by the City, whose opposition is,
as submitted by Seletje Construction, nothing more than an appeal against the
findings of the Arbitrator disguised as a review . It fails to meet the stringent
threshold for relief under s 33(1), and its application is both procedurally
defective and substantively unmeritorious.
[35]. Whilst it is so that there may have been compliance with certain parts of
the Award, such as the orders relating to payment of monetary sums, it is so, as
contended on behalf of Seletje Construction, that this does not prevent the
Award from being made an Order of Court in terms of s 3 1(1). Compliance with
one part of an award does not extinguish the award itself. The Arbitration Act
does not envisage a ‘partial enforcement’ process. The Applicant is entitled to
rely on the award as a whole and is not requi red to isolate portions that may
have been informally or inadequately addressed.
[36]. Accordingly, Seletje Construction’s application to have the Arbitrator’ s
[36]. Accordingly, Seletje Construction’s application to have the Arbitrator’ s
award made an Order of Court should be granted and the counter-application of
the City of Ekurhuleni falls to be dismissed with costs . In view of my findings
relating to the merits of the counter -application, which imply that the counter -
15
application had no reasonable prospects of success, the City’s condonation
application should also be dismissed.
Costs
[37]. The general rule in matters of costs is that the successful party should be
given his costs, and this rule should not be departed from except where there
are good grounds for doing so , such as misconduct on the part of the
successful party or other exceptional circumstances. See: Myers v Abramson3.
[38]. I can think of no reason why I should deviate from this general rule. The
applicant should therefore be granted its costs of its main application, as well as
the costs relating to the respondent’s counter-application.
Order
[39]. In the result, I make the following order:
(1) The Arbitration Award dated 3 July 202 1 by the Arbitrator, Mr P F
Rossouw SC, and handed down / published by him on 1 September 2021,
be and is hereby made an Order of this Court.
(2) The respondent shall pay the applicant’s costs of this opposed application,
including the costs of Counsel on scale ‘C’ of the applicable tariff provided
for in the Uniform Rules of Court.
(3) The respondent’s application for condonation be and is hereby dismissed
with costs.
(4) The respondent’s counter -application be and is hereby dismissed with
costs.
(5) The respondent shall pay the applicant’s costs of the opposed
condonation application and the oppose counter-application, such costs to
include the costs consequent upon the utilisation of Counsel on scale ‘C’
of the applicable tariff provided for in the Uniform Rules of Court.
3 Myers v Abrahamson 1951(3) SA 438 (C) at 455
16
_____________________ _______
L R ADAMS
Judge of the High Court
Gauteng Division, Johannesburg
17
HEARD ON: 20 May 2025
JUDGMENT DATE:
17 September 2025 –
Judgment handed down
electronically
FOR THE APPLICANT: D Thumbati
INSTRUCTED BY: Ledwaba Zwai Attorney,
Pretoria
FOR THE RESPONDENT: J C Uys SC
INSTRUCTED BY:
Klopper Jonker
Incorporated,
New Redruth, Alberton